top of page

Terms and Conditions

These Terms and Conditions apply to all quotations, orders, supply, and installation of fitted furniture by Advanced Interiors (“we”, “us”, “our”). By paying the deposit, you (“the Customer”) agree to these Terms and Conditions, which form a legally binding contract.

 

1. Quotations, Plans and Specifications

1.1 All quotations are based on the drawings, plans, and specifications included in your personalised quotation.

1.2 You confirm that you have carefully checked and approved all drawings, plans, and specifications prior to paying the deposit.

1.3 You acknowledge that only the units, materials, finishes, and accessories specified in the quotation and drawings will be supplied.

1.4 All drawings are illustrative and not to precise scale. We reserve the right to make reasonable amendments to dimensions, layouts, or specifications where necessary, provided such changes do not materially affect the overall design, functionality, or agreed outcome.

 

2. Deposit and Formation of Contract

2.1 A deposit of 75% of the total quoted price is required to proceed with your order.

2.2 Payment of the deposit:

  • Secures your installation (fit) date

  • Confirms your acceptance of these Terms and Conditions

  • Creates a legally binding contract between you and Advanced Interiors

2.3 Once the deposit is received and your order has been placed into production, we will begin manufacturing your bespoke goods.

 

3. Balance Payment

3.1 The remaining 25% balance is due upon practical completion of the installation.

3.2 Practical completion means the works are substantially complete and fit for their intended use, subject only to minor snagging items which do not prevent normal use.

3.3 We reserve the right to request payment promptly upon practical completion of the works.

 

4. Cancellation and Refunds

4.1 As your goods are made to your bespoke specifications, you acknowledge that cancellation rights under the Consumer Contracts (Information, Cancellation and Additional Charges) Regulations 2013 do not apply once production has commenced.

4.2 If you cancel your order:

  • Prior to production, we may retain a reasonable amount of the deposit to cover design work, administration, and any costs incurred

  • After production has commenced, the deposit is non-refundable except where required by law

4.3 We reserve the right to cancel your order at any time. In such circumstances:

  • You will be notified as soon as reasonably possible

  • Any monies paid will be refunded in full

 

5. Ownership of Goods

5.1 All goods supplied remain the property of Advanced Interiors until full payment has been received.

5.2 Legal ownership of the goods will not pass to you until all sums due under the contract have been paid in full.

5.3 Responsibility for the goods passes to you upon installation at your property.

 

6. Supply and Installation

6.1 We will supply and fit the goods at the agreed installation address unless otherwise stated in your quotation.

6.2 If the supply or installation of the goods is delayed due to circumstances beyond our reasonable control, we will:

  • Inform you as soon as reasonably possible

  • Take reasonable steps to minimise the delay

  • Arrange an alternative installation date with you

6.3 We will not be liable for delays or failure to perform our obligations where this is due to events beyond our reasonable control, provided we act reasonably to mitigate the impact and complete the works as soon as practicable.

 

7. Customer Responsibilities

You agree to the following:

7.1 Access and Site Conditions

  • Provide reasonable access to the property between 8:00am and 6:30pm, or as otherwise agreed

  • Ensure safe and suitable working conditions

  • Provide sufficient space for installation by clearing the relevant areas

  • Ladder-only access is not acceptable

7.2 Preparatory Works

  • Ensure all plumbing, gas, drainage, radiators, and electrical works are completed prior to installation

  • Ensure removal of existing furniture, flooring, and carpets has been completed

  • All preparatory work must be completed to a good and workmanlike standard

7.3 Utilities

  • Provide access to a standard 13A 240V mains electricity supply free of charge

  • Ensure the electrical supply complies with applicable safety standards

7.4 Property and Structural Conditions

  • Confirm that walls and fixing surfaces are structurally sound

  • Inform us in advance of any site conditions or construction features that may affect installation

7.5 Changes to Site

  • Not make material alterations to the installation area after entering into the contract without informing us

  • This includes installing, removing, or relocating fixed items

 

8. Installation and Finishing

8.1 We recommend that rooms are not decorated prior to installation, as minor incidental damage may occur during fitting.

8.2 We will take reasonable care during installation. However, we are not responsible for minor and unavoidable incidental damage that may occur as part of the normal installation process, provided we have exercised reasonable care and skill.

8.3 For practical and safety reasons, materials over 2500mm may include joins.

 

9. Product Specification and Appearance

9.1 All products are manufactured to a high standard using appropriate materials and workmanship.

9.2 While we make every effort to match colours, finishes, and grains to samples or designs:

  • Variations may occur due to lighting conditions

  • Natural materials may display inherent variations

These variations shall not be considered defects.

 

10. Insolvency

10.1 This contract may be terminated if you:

  • Become bankrupt or insolvent, or

  • Enter into any arrangement with your creditors

10.2 In such circumstances, we reserve the right to:

  • Cease further work

  • Retain payment for work already completed and costs reasonably incurred

 

11. Limitation of Liability

11.1 Nothing in these Terms and Conditions limits or excludes liability for:

  • Death or personal injury caused by negligence

  • Fraud or fraudulent misrepresentation

  • Any matter which cannot be excluded or limited under applicable law

11.2 Subject to clause 11.1, we shall only be liable for losses that are a foreseeable consequence of our breach of contract, and we will not be liable for indirect or consequential losses.

 

12. Late Payment

12.1 If any payment is not made when due, we reserve the right to charge interest on the overdue amount at a reasonable rate in accordance with applicable law.

12.2 We may also suspend further work or withhold completion until payment is received.

 

13. Complaints

13.1 If you have any concerns or complaints, please contact us using the details below and we will aim to resolve the issue promptly and fairly.

 

14. Governing Law

14.1 This contract shall be governed by and interpreted in accordance with the laws of England and Wales.

14.2 The parties agree that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim arising out of or in connection with this contract.

 

15. General

15.1 These Terms and Conditions form the entire agreement between you and Advanced Interiors.

15.2 If any provision is found to be invalid or unenforceable, the remaining provisions shall remain in full force.

15.3 Nothing in these Terms and Conditions affects your statutory rights under applicable law.

 

Contact Details

Advanced Interiors
Phone: 07867 524331
Email: info.advancedinteriors@gmail.com

Fitted Furniture Specialists

bottom of page